Terms & Conditions

1. AGREEMENT TO TERMS

These Terms and Conditions ("Terms") govern all services provided by VT Enterprises ("Company," "we," "our," or "us") to any client, customer, property owner, developer, vendor, or third party ("Client," "you," or "your").

By engaging our services, signing any proposal, estimate, or project agreement, submitting a deposit, or otherwise authorizing work to begin, you agree to be legally bound by these Terms.

If you do not agree, you may not engage our services.

2. SERVICES

VT Enterprises provides construction and development services including, but not limited to:

• Residential and commercial construction
• Renovations and remodeling
• New construction and development projects
• Project management and oversight
• Contractor coordination
• Construction consulting and feasibility analysis

Each project is governed by a written proposal, estimate, or contract outlining scope, pricing, and timelines. In the event of conflict, the signed project agreement controls.

3. GOVERNING LAW & JURISDICTION

These Terms are governed by the laws of the State of Tennessee, without regard to conflict-of-law principles, unless otherwise specified in a project-specific written agreement.

Any dispute arising out of or relating to these Terms or services shall be resolved in the courts located in Tennessee.

4. CLIENT REPRESENTATIONS

The Client represents and warrants that:

• They are the lawful owner of the property or have legal authority to authorize work.
• All information provided is accurate and complete.
• Required HOA, zoning, or private approvals have been disclosed.
• They will provide timely decisions, approvals, and access to the property.

Failure to provide access, approvals, or accurate information may result in delays and additional costs.

5. PERMITS & REGULATORY COMPLIANCE

Where applicable, VT Enterprises may assist with permit applications and inspections. However:

• Approval is solely at the discretion of the governing authority.
• We are not responsible for municipal delays.
• Code changes or regulatory updates may require scope or cost adjustments.
• The Client remains responsible for compliance with all property-specific restrictions not disclosed to us.

6. PAYMENT TERMS

Payment terms are defined in each project agreement.

Unless otherwise stated:

• All fees are in USD.
• Deposits may be required before work begins.
• Payments are due per milestone schedule.
• Late payments may result in suspension of work.
• Change Orders must be approved in writing and may affect cost and timeline.
• Failure to make payment may result in mechanic's lien rights being exercised as permitted by law.

7. DELAYS & FORCE MAJEURE

VT Enterprises is not liable for delays caused by:

• Weather or natural disasters
• Labor shortages
• Supply chain disruptions
• Government actions
• Unforeseen site conditions
• Client-requested changes
• Third parties not under our control

Timelines are estimates unless expressly guaranteed in writing.

8. INTELLECTUAL PROPERTY

All drawings, plans, schedules, estimates, and documentation created by VT Enterprises remain our intellectual property unless explicitly transferred in writing.

Unauthorized reuse, duplication, or distribution is prohibited.

9. WARRANTIES

We warrant that work will be performed in a professional manner consistent with industry standards.

Unless otherwise stated in a project agreement:

• No express or implied warranties are made beyond applicable law.
• Manufacturer warranties apply to materials and products where applicable.

10. LIMITATION OF LIABILITY

To the fullest extent permitted by law:

• Our total liability shall not exceed the total amount paid by the Client for the project giving rise to the claim.
• We are not liable for indirect, incidental, consequential, or special damages.
• We are not responsible for loss of profits, business interruption, or financing delays.

11. TERMINATION

Either party may terminate a project in accordance with the signed project agreement.

Upon termination:

• The Client must pay for all completed work and materials ordered.
• Deposits may be non-refundable as specified in the agreement.

12. SMS COMMUNICATIONS TERMS

By providing your mobile phone number to VT Enterprises, you consent to receive SMS messages related to:

• Appointment reminders
• Project updates
• Scheduling coordination
• Service notifications

Message frequency may vary.

Message and data rates may apply.

You may opt out at any time by replying STOP.

For assistance, reply HELP or contact jt@trevelosa.com.

Carriers are not liable for delayed or undelivered messages.

You must be at least 18 years old to receive SMS communications.

13. MODIFICATIONS

We reserve the right to update these Terms. Updated Terms apply to future engagements unless otherwise agreed in writing.